Condominium Act
Index
- MCL 559.101 Short Title
- MCL 559.102 Meanings of Words and Phrases
- MCL 559.103 Definitions; a to C
- MCL 559.104 Definitions; C
- MCL 559.105 Definitions; C
- MCL 559.106 Definitions; C to G
- MCL 559.107 Definitions; L to M
- MCL 559.108 "Master Deed" Defined
- MCL 559.109 Definitions; P
- MCL 559.110 Definitions; R to T
- MCL 559.111 Offering Residential Condominium For Sale; Compliance With Occupational Code Required
- MCL 559.115 Construction Or Interpretation of Act
- MCL 559.121 Offering Condominium Unit Or Project For Sale; Liabilities and Penalties; Duties of Developer; Compliance By Association of Co-Owners
- MCL 559.131 Condominium Project Containing Convertible Area; Contents of Master Deed
- MCL 559.132 Expandable Condominium Project; Contents of Master Deed
- MCL 559.133 Contractable Condominium Project; Contents of Master Deed
- MCL 559.134 Leasehold Condominium Project; Lease Terms; Required Contents of Master Deed; Termination of Co-Owner's Leasehold Interest By Lessor Prohibited
- MCL 559.135 Easements; Creation; Description; Contents
- MCL 559.136 Addition of Undivided Interests In Land As Common Elements; Tenancy of Co-Owners; Condominium Unit On Lands Prohibited; Description In Master Deed
- MCL 559.137 Allocation to Condominium Unit of Undivided Interest In Common Elements Proportionate to Percentage of Value Assigned; Statement, Table, Exhibit, Or Schedule In Master Deed; Formula; Basis of Reallocation; Allocating Percentage of Value to Convertible Space; Alteration of Undivided Interest In Common Elements; Partition of Common Elements
- MCL 559.138 Creation of Condominium Units Within Convertible Or Additional Lands; Allocation of Interests In Common Elements; Amended Master Deed and Condominium Subdivision Plan; Revised Schedule
- MCL 559.139 Assignment and Reassignment of Limited Common Elements; Application; Amendment to Master Deed
- MCL 559.140 Easement For Encroachment
- MCL 559.141 Conversion of Convertible Area Into Condominium Units Or Common Elements; Amendment; Identifying Number; Allocating Portion of Undivided Interest; Description of Limited Common Elements
- MCL 559.143 Expansion, Contraction, Or Conversion of Land Or Space; Time of Occurrence; Consolidating Master Deed
- MCL 559.144 Transferable Easement As to Common Elements For Purpose of Making Improvements
- MCL 559.145 Offices, Model Units, and Other Facilities; Maintenance; Costs; Restoration of Facilities
- MCL 559.146 Restrictions and Covenants
- MCL 559.147 Improvements Or Alterations By Co-Owners
- MCL 559.147a Persons With Disabilities; Improvements Or Modifications By Co-Owner to Facilitate Access Or Movement; Alleviation of Hazardous Conditions
- MCL 559.148 Relocation of Boundaries Between Adjoining Condominium Units
- MCL 559.149 Subdivision of Condominium Units
- MCL 559.150 Termination of Condominium Project Or Amendment of Master Deed By Developer
- MCL 559.151 Termination of Condominium Project By Agreement of Developer and Unaffiliated Co-Owners
- MCL 559.152 Advisory Committee of Nondeveloper Co-Owners; Establishment; Meeting With Condominium Project Board of Directors; Cessation; Right to Elect Directors; Formula; Recording Consolidating Master Deed; Copy; "Units that May Be Created" Defined; Time of Sale to Nondeveloper Co-Owner
- MCL 559.153 Bylaws Governing Administration of Condominium Project; Amendments; Recording
- MCL 559.154 Bylaws; Mandatory Provisions; Allocation of Votes; Dispute, Claim, Or Grievance; Applicability of Subsections (8), (9), and (10)
- MCL 559.155 Voiding Service Contract and Management Contract
- MCL 559.156 Bylaws; Permissible Provisions
- MCL 559.156a Displaying United States Flag On Condominium Unit; Applicability of Section
- MCL 559.157 Books, Records, Contracts, and Financial Statements; Examination; Audit Or Review; Opt-Out of Requirements of Subsection (2)
- MCL 559.158 Acquisition of Title By Foreclosure of First Mortgage; Liability For Assessments
- MCL 559.159 Submission of Property With Mortgage of Record
- MCL 559.160 Action On Behalf of and Against Co-Owners
- MCL 559.161 Condominium Unit As Sole Property
- MCL 559.162 Ownership of Condominium Unit
- MCL 559.163 Rights of Co-Owner
- MCL 559.164 Conveyance and Other Instruments Affecting Title to Condominium Unit; Description of Unit; Recordation
- MCL 559.165 Compliance With Master Deed, Bylaws, Rules, and Regulations
- MCL 559.166 Condominium Subdivision Plan; Preparation; Signature and Seal; Contents; Recording; Structures and Improvements to Be Completed By Developer
- MCL 559.167 Change In Condominium Project; Amendment; Replat of Condominium Subdivision Plan; Right of Withdrawal; Reversion of Undeveloped Land to General Common Elements; Election, Notice, and Recording Requirements; Applicability of Subsections (3) and (4); "Undeveloped Land" Defined
- MCL 559.168 Availability of Condominium Documents
- MCL 559.169 Assessment of Common Expenses; Contribution of Co-Owner
- MCL 559.170 [Repealed]
- MCL 559.171 Notice of Proposed Action
- MCL 559.171a Rules Applicable to Condominium Project Not Served By Public Water and Public Sewers; Submission of Plan to Department of Public Health; Approval Or Rejection
- MCL 559.172 Establishment of Condominium Project; Sale of Condominium Unit Before Master Deed Recorded Prohibited; Exception; Substantial Failure of Master Deed to Comply With Act; Marketability of Title
- MCL 559.172a Recordation of Master Deed; Creation of Time-Share Unit; Amendment of Documents As Material Alteration
- MCL 559.172b Air Space Over Fee
- MCL 559.173 Recordation of Master Deed and Amendment; Certification By Treasurer; Filing Copy of Master Deed With Local Supervisor Or Assessing Officer; Filing Architectural Plans and Specifications Or Affidavit With Local Unit of Government
- MCL 559.174 Delivery and Retention of Condominium Subdivision Plan; Recordation of Consolidating Master Deed
- MCL 559.181 Service of Process
- MCL 559.181a Promotional Material; Labeling Structure Or Improvement "Need Not Be Built"
- MCL 559.182 [Repealed]
- MCL 559.183 Preliminary Reservation Agreement; Use; Condominium Buyer's Handbook; Placing Payment In Escrow; Cancellation of Agreement; Refund; Treating Payment As If Made Under Purchase Agreement
- MCL 559.184 Inapplicable to Business Condominium Unit; Withdrawal From Signed Purchase Agreement; Depositing and Retaining Funds In Escrow; Contents of Purchase Agreement; Waiver of Right of Withdrawal; Form
- MCL 559.184a Providing Copies of Listed Documents to Prospective Purchaser of Condominium Unit; Amendment to Purchase Agreement and Condominium Documents; Signature On Form As Evidence; Providing Prospective Purchaser of Business Condominium Unit Copy of Recorded Master Deed; Misleading Statements; Violation
- MCL 559.185 Liquidated Damages In Case of Default; Actual Damages; Receipt of Escrowed Funds
- MCL 559.186, 559.187 [Repealed]
- MCL 559.188 Offering For Sale and Entering Into Purchase Agreement With Respect to Condominium Unit Proposed to Be Included Within Additional Land of Expandable Condominium Or Within Convertible Land Without Recording Amended Master Deed
- MCL 559.189 [Repealed]
- MCL 559.190 Amendment of Condominium Documents; Consent; Void Provision Superseded By Subsection (2); Reservation of Right to Amend; Notice of Proposed Amendments; Costs and Expenses; Master Deed Amendment; Affirmative Vote
- MCL 559.190a Voting Procedures
- MCL 559.191 Recording of Amendment to Recorded Condominium Document Required; Copy to Co-Owner
- MCL 559.192, 559.193 [Repealed]
- MCL 559.194 Title Insurance Policy
- MCL 559.195 Revision of Condominium Subdivision Plan; Altering Percentage of Value; Revisions In Percentage of Value Per Condominium Unit
- MCL 559.201-559.203 [Repealed]
- MCL 559.203a [Repealed]
- MCL 559.203b Inapplicable to Business Condominium Unit; Release of Deposits Or Amounts Retained In Escrow; Conditions; Substantial Completion; Furnishing Escrow Agent With Evidence of Adequate Security In Place of Retaining Funds; Certificate; Notice to Developer; Release of Interest Paid On Amounts Escrowed; Escrow Agent Deemed Independent Party; Liability; Certification By Licensed Professional Architect Or Engineer; "Licensed Professional Engineer Or Architect" Defined
- MCL 559.204 Conversion Condominium Project; Notice; Termination of Tenancy
- MCL 559.204a Terminating Tenancy of Certain Persons Without Cause Prohibited; Criteria; Notice
- MCL 559.204b Definitions; Applicability of Section; Notice of Right to Elect Extended Lease Arrangement; Election; Extended Lease Arrangement Provisions; Number of Years Lease Renewable; Notice By Developer Entering Into Restricted Lease Arrangement; Assignment, Device, Sublease, Or Transfer of Lease By Qualified Senior Citizen Or Person With Disabilities Prohibited; Automatic Termination of Lease; Liability of Lessor Violating Rental Restrictions; Recovery of Possession of Restricted Unit; Transfer of Restricted Unit
- MCL 559.204c [Repealed]
- MCL 559.204d Developer Not Required to Offer Extended Lease Arrangement; Conditions; Compliance
- MCL 559.204e Legislative Intent; Examination of Relevant Information; Recommendation
- MCL 559.205 Reserve Fund
- MCL 559.206 Default By Co-Owner; Relief
- MCL 559.207 Action to Enforce Terms and Provisions of Condominium Documents; Action For Injunctive Relief Or Damages
- MCL 559.208 Assessment Lien; Priority; Foreclosure; Bid; Actions; Receiver
- MCL 559.209 Liability For Torts
- MCL 559.210 [Repealed]
- MCL 559.211 Sale Or Conveyance of Condominium Unit; Payment and Statement of Unpaid Assessments; Liability For Unpaid Assessments
- MCL 559.212 Renting Or Leasing Condominium Unit; Disclosure; Review of Lease Form; Notice; Compliance Required; Action By Association Upon Noncompliance; Notice of Arrearage; Deduction of Arrearage and Future Assessments From Rental Payments
- MCL 559.213 Financing
- MCL 559.214 Homestead Exemption
- MCL 559.215 Action By Person Or Association Adversely Affected By Violation of Or Failure to Comply With Act, Rules, Agreement, Or Master Deed; Costs; Violation of Mcl 559.121 Or 559.184a; Liability
- MCL 559.221 Mobile Home Condominium Project; Establishment, Operation, and Regulation; Compliance
- MCL 559.222 Mobile Home Condominium Project; Disclosure
- MCL 559.222a Mobile Home Conversion Condominium Project; Notification of Tenants; Termination of Tenancy
- MCL 559.222b Extended Lease Arrangement
- MCL 559.223 Mobile Home Condominium Project; Leasing Agreements
- MCL 559.224 Title to Mobile Home Condominium Site; Undivided Interest In Common Elements; Removal of Mobile Home; Sale of Site
- MCL 559.225, 559.226 [Repealed]
- MCL 559.227 Compliance By Developer of Mobile Home Condominium; Prohibited Requirements
- MCL 559.231 Special Assessments and Property Taxes
- MCL 559.232 Construction Lien; Limitations
- MCL 559.233 Eminent Domain
- MCL 559.234 Recreational Facilities and Other Amenities; Compliance
- MCL 559.235 Successor Developer
- MCL 559.236 [Repealed]
- MCL 559.237 Obligations of Developer Not Affected By Transfer of Interest
- MCL 559.238 [Repealed]
- MCL 559.239 Complaint For Nonpayment of Assessments; Answer; Set Off
- MCL 559.240 Reproduction of Document; Certified Reproduction Or Certification As Evidence
- MCL 559.241 Law, Ordinance, Or Regulation of Local Unit of Government; Limitations
- MCL 559.242 Promulgation of Rules, Forms, and Orders; Definition of Terms
- MCL 559.244 Contract to Settle By Arbitration; Execution; Option; Period of Limitations; Allocation of Costs; Conduct; Appointment of Arbitrator; Procedures; Rules; Arbitration Award As Binding
- MCL 559.245 Complaint Copy to Developer; Notice of Available Remedies
- MCL 559.250 Discretionary Powers of Administrator; Exercise
- MCL 559.251-559.255 [Repealed]
- MCL 559.256 Prohibited Representations
- MCL 559.257 [Repealed]
- MCL 559.258 Prohibited Conduct As Misdemeanor; Penalty; Violation As Separate Offense; Consecutive Terms of Imprisonment; Aggregate Fines; Action By Prosecuting Attorney Or Department of Attorney General
- MCL 559.259 Injunction
- MCL 559.260 [Repealed]
- MCL 559.270 Effect of Act and 1982 Amendatory Act; Consummation of Proceedings; Continuation Or Institution of Proceedings
- MCL 559.271 Repeal of Mcl 559.1 to 559.31
- MCL 559.272 Effective Date; Requirements For Disclosure Statement
- MCL 559.273 Applicability of Amendatory Act; Applicability of Certain Subsections
- MCL 559.274 [Repealed]
- MCL 559.275 Powers of Administrator
- MCL 559.276 Statute of Limitations